DECVILLA by LANDROOF Pvt Ltd., (hereinafter referred to as “DECVILLA”, “Company”, “we”, “our” or “us”) is engaged in the business of providing consultancy and execution of residential/commercial interior work/designing services and other incidental services (“Services”).
These terms of use describe and govern the terms and conditions on which the Client (“Client” or “you”,” your”) can obtain Services from the Company (referred to as “Terms”). By accessing and using our home interior solutions and services, you acknowledge that you have read, understood and agreed to be bound by the terms and conditions governing interior design projects undertaken by DECVILLA by LANDROOF Pvt Ltd. The Client acknowledges that these documents may be updated periodically, and it is the Client’s responsibility to review the Terms and Conditions regularly. Continued use of the Service after any such changes constitutes acceptance of the new Terms and Conditions and Privacy Policy.
1. Project and Order
1.1 Project and Order:
A project refers to home design undertaking for a single home. Multiple orders can be placed for a single project (for e.g., one order for modular products, a separate one for services such as civil work). Payments and execution timelines are processed on an order level. The minimum order value that will be executed by Interior Company shall not be less than INR 3 lakh.
1.2. Estimated project quote:
This quote is indicative and generated based on your current requirements. As a quote is affected by the design, product, materials, colours and services you choose, it is subject to change. Please speak to your designer to understand how she/he can work around a budget.
1.3.
If the project scope or value is changed at the execution stage, then any free gift(s)/discounts offered during the time of sale shall stand withdrawn.
1.4. Amendment of BOQ post publication:
Upon the mutual agreement and finalization of the quote between DECVILLA and the Client, the quote shall be considered complete and definitive. Once the project reaches the execution stage, no changes shall be made to the quote, regardless of whether the value of the changes or items proposed is similar to those in the finalized quote. The Client agrees that the finalized quote accurately reflects the scope of work, materials.
2. Payment Terms
2.1. Booking Fee and Refunds
2.1.1 A project can have multiple order types based on the type of scope of work (e.g a single project can have multiple orders like modular work, on-site services and store products). Payment terms will vary on order level.
2.1.2 Booking fee: Your booking fee (10% payment) is adjusted against future
2.1.3 Refunds: Once the project is booked, you are provided with a 72-hour free look window during which you may choose to cancel the project. After this window, no refunds will be provided if the project is cancelled.
2.2. Payment Schedule
2.2.1 Payment terms shall be based on and shall vary on order
Order Type
Booking Fees
Place Order
Execution stages**/ Prior to Delivery
Project (Modular + custom services)
10%
40%
25% (50% work) + 25% (90% work)
2.2.2 If the scope of your project increases significantly, you shall be required to pay 10% for the new scope before the design can begin.
3. Quote Validity
3.2 Once the 10% booking amount is paid by the Client, the prices will be locked for 60 days. However, if the project does not proceed to execution within this period, the prices may change.
3.3Any modifications to the proposal, such as changes in scope or requirements, may result in a change in price. Please note that these prices are specific to this project.
4. Delivery
4.1 Estimated Delivery Timeline
4.1.2 An estimated delivery timeline will be provided within 5 days of order placement subject to the scope of
4.1.3 The approximate Delivery Time of the Project from the time of placing the order is as follows –
Delivery Timeline
Project Value
Number of Days
0-5 Lakhs
45
5-8 Lakhs
55
8-12 Lakhs
70
12-15 Lakhs
80
15-20 Lakhs
90
20 Lakhs+
NIL
4.2. Pre-Conditions for on time delivery (Delivery Guarantee)
4.2.1. The Delivery Guarantee shall not be applicable in the following cases.
- If the site has restrictions on work timings during the
- If the Client is not in full possession of the site and temporary possession has been allowed by the
- If there is concurrent work being done at the site by any other third-party contractor like painting, wallpaper, wooden flooring or carpentry work, during installation, civil works.
- If there are any changes to designs after the order is in
- If the Customer is living at the site at the time of
- Abnormal hindrances in execution like continuous lack of power, non-working lifts, no permission from builder,
- If any litigation related to the property, site or any other issues related to the client or builder, or any third party disrupts the work of DECVILLA.
- A Force Majeure event occurs. (A Force Majeure event refers to the acts of God including; such as flooding, hurricanes, earthquakes, lightning, any natural calamities etc., environmental conditions such as air pollution, solvent exposure, mold, mildew etc., or staining from foreign substances such as dirt, grease, oils, sprays etc. fire, acts of war, acts of terrorism, pandemic, lockdown, acts of Government or any other event which is beyond the control of DECVILLA).
- If the client does not respond to the payment link or make payment within 48 hours of its generation, it may adversely impact the Delivery Guarantee. DECVILLA reserves the right to adjust the project schedule
- Store furniture’s delivery timeline shall be shared on a case-to-case basis to the
5. Order Placement and Execution
5.2 Execution stages: Execution stages help us track the progress of your order. They mark the completion of an important activity at which balance payment (for that order type) will be due. DECVILLA shall proceed with completing the rest of the order only after the amount due for that execution stage has been paid for. The following table defines execution stages for the different types of orders.
Delivery Timeline
Item
Execution Stage
Order type 1 - Services such as civil work, custom furniture
Based on the scope of your project, 50% of your order value (s) will be due.
Order type 2 - Marketplace furniture, decor items, modular products (such as kitchen).
Execution Stage
5.4 Unloading Services: Any movement of materials by stairs above 2nd floor will attract the following additional charge/s:
- A fixed unloading charge of Rs. 5000 shall be charged for the movement of material from 3rd floor and above where the service lift is unavailable.
- An additional charge of Rs. 1000 will be applicable for each floor movement of material from the 9th floor and above, where the service lift is unavailable.
6. Delay Penalties
6.1 DECVILLA will be liable to pay a delay penalty @ INR 500 per day for delay in handover of the project beyond 15 working days (excluding Sundays and Public Holidays) from the confirmed Handover Date. The confirmed Handover Date is communicated in the Client Service Agreement; however, it is linked to all payments made by the client as per the schedule and all sales orders for the project are raised.
6.2 Delay penalty is only applicable if all the norms as per DECVILLA Delivery Guarantee is
6.3 The maximum delay penalty payable cannot exceed 3% of the total project
6.4 Delay penalty would be paid out through a refund to the customer’s bank account provided the client has paid 100% of the Project Amount as per schedule and Completion of Handover.
6.5 Delay Due to Restricted Access: The Client has the obligation to provide free, complete, unrestricted access and handover of the site where the interior work has to be executed. In case of delay in the above or subsequent disruptions in access or freedom to execute the work by the DECVILLA and/or its employees/ teams, the agreed Handover Date and the delivery timeline shall stand terminated with immediate effect.
6.6 A new Handover Date and delivery timeline shall be negotiated and mutually agreed upon by both Parties. DECVILLA shall not be liable to pay to the Client any delay penalty in such scenario.
7. Invoicing
7.2 Invoices for the design service, products and other services shall be raised by DECVILLA by LANDROOF Pvt
7.3 Product invoicing for all branded products will be done by the authorized sellers/distributors of such For any queries, please get in touch with your DECVILLA’s representative.
8. Governing Law, Jurisdiction and Dispute Resolution
8.2 The Dispute Resolution proceedings shall be conducted either electronically or through physical hearing, in accordance with the Rules of such Dispute Resolution Institution and in compliance with the Arbitration and Conciliation Act, 1996. The proceedings shall be conducted in English, and the jurisdiction shall be Pune.
8.3 The award passed by the Dispute Resolution Institution shall be final and binding on the Parties and the Parties agree to be bound thereby and to act accordingly. The award shall be enforceable in any competent court of law.
8.4 This Agreement will be governed by laws prevailing in India and this Agreement shall be subject to the exclusive jurisdiction of the courts at Pune.
9. Returns and Replacements
9.2 Post-Order Placement: DECVILLA cannot cancel, replace or modify items once the order is placed since each item is made to order.
9.3 OEM Replacements: OEM (Original Equipment Manufacturer) replacements due to functional defects found at the time of handover are outside the Delivery Guarantee. The replacements will be done free of cost based on the OEM timeline and DECVILLA will facilitate the replacements. Eg. hardware, appliances like hob and chimney, accessories, colour mismatch or scratches in handles, etc.
9.4 Marketplace Products: All furniture, decor, appliances and accessories which belong to the DECVILLA’s brand partners are referred to as “Marketplace Products”. Products with non-manufacturing defects and damage post-delivery are not eligible for returns or replacements.
Explore the Best Interior Designers for Your Home at Interior Company
Are you in the midst of a home renovation? Interior Company specialises in expertly guiding and managing every aspect of crafting a home, whether it involves new construction or furnishing. Our dedicated team of interior designers understands every home is unique and seeks each project with fresh eyes, infusing creativity and
Read More...
Lowest Price Guarantee
No false claims. You get what you see. Lowest Price Guaranteed on home interiors.
Timely Delivery Assurance
Promised Timeline = Actual Date of Delivery. We strictly follow the timelines promised to you
No Cost EMI Option Available Upto 10 Lacs**
Get in touch with us!
A descriptive paragraph that tells clients how good you are and proves that you are the best choice.
Our Company
Interiors
Contact Info
- Office No-521, Gera imperium rise, Phase-2 Hinjewadi Pune – 411057.
- 8855043041
- pune.decvilla@gmail.com